Terms of Service

Advocate Construction LLC

Last Updated: January 30, 2026

1. AGREEMENT TO TERMS

These Terms of Service ("Terms") constitute a legally binding agreement between you ("Customer," "you," or "your") and Advocate Construction LLC ("Advocate Construction," "we," "our," or "us"), a Illinois Limited Liability Company, with our principal place of business at 827 North Ave, Glendale Heights Illinois 60139.

By accessing or using our website (https://advocateconstruction.com/), submitting a contact form, requesting an estimate, scheduling a consultation, entering into a service agreement, or otherwise engaging with our services, you agree to be bound by these Terms and our Privacy Policy.

IF YOU DO NOT AGREE TO THESE TERMS, DO NOT USE OUR WEBSITE OR SERVICES.

2. SMS/TEXT MESSAGE TERMS AND CONDITIONS

2.1 SMS Program Description

Advocate Construction offers an SMS (text message) communication program to provide you with convenient updates, reminders, and information about our services. By providing your mobile phone number and opting in to receive text messages, you consent to receive the following types of messages:

Transactional Messages:

Appointment confirmations and reminders

Project status updates and progress notifications

Scheduling changes or delays

Payment confirmations and billing reminders

Important safety notifications related to your project

Permit and inspection status updates

Delivery and material arrival notifications

Emergency project communications

Final walk-through and completion notifications

Marketing Messages (if you opt-in):

Promotional offers and seasonal discounts

Special financing opportunities

New service announcements

Project portfolio showcases

Customer referral program information

Educational content about home improvement

Company news and updates

2.2 How to Opt-In to SMS Messages

You may opt-in to receive SMS messages from Advocate Construction through the following methods:

Website Forms: By checking the SMS consent box on any contact form, quote request form, or appointment booking form on our website

Verbal Consent: By providing verbal consent during phone conversations with our team (consent will be documented)

Text-to-Join: By texting a keyword (such as "JOIN," "START,") to our business number

In-Person Consent: By providing written consent during in-home consultations or contract signings

By opting in, you provide your express written consent to receive automated and/or marketing text messages at the mobile phone number you provide, using an automatic telephone dialing system or an artificial or prerecorded voice. Consent to receive marketing messages is NOT required as a condition of purchasing any goods or services from Advocate Construction.

2.3 Message Frequency

Transactional Messages: Message frequency varies based on your project activity. During active projects, you may receive up to 10 messages per month. Outside of active projects, you may receive occasional follow-up messages.

Marketing Messages: If you opt-in to marketing communications, you may receive up to 4 promotional messages per month.

Total Messages: You may receive a maximum of 15 messages per month during active projects with marketing opt-in.

2.4 Message & Data Rate Disclosure

Standard message and data rates may apply. Message and data rates are determined by your mobile carrier and are your responsibility. Advocate Construction does not charge for text messages, but your wireless carrier may charge you for messages sent and received. The number of messages you receive will depend on your project status and communication preferences. Check with your mobile carrier for details about your text messaging plan and any applicable charges.

2.5 How to Opt-Out of SMS Messages

You can opt-out of receiving text messages at any time, free of charge, through the following methods:

Reply STOP: Text "STOP," "END," "CANCEL," "UNSUBSCRIBE," or "QUIT" to any message from us

Reply HELP: Text "HELP" to any message from us for assistance or customer support

Email Request: Email us at [email protected] with your request to stop receiving text messages

Call Us: Call (630) 398-4600 and request to be removed from our SMS program

Written Request: Mail your opt-out request to: Advocate Construction LLC, ATTN: SMS Opt-Out, 374 Upland Dr #1st, Tukwila, WA 98188

What Happens After You Opt-Out:

You will receive one final confirmation message acknowledging your opt-out request

You will no longer receive marketing or promotional text messages

You may still receive critical transactional messages related to active projects, such as urgent safety notifications, emergency schedule changes, or legally required communications

You can opt back in at any time by texting "START" or "JOIN" to our business number or by contacting us using any of the methods above

2.6 Customer Support Contact Information

For questions, concerns, or assistance with our SMS program, contact us:

Email: [email protected]

Phone: (630) 398-4600 (Monday - Friday, 9:00 AM - 5:00 PM PST)

Mail: Advocate Construction LLC, 827 North Ave, Glendale Heights Illinois 60139

Website: https://advocateconstruction.com/

Our customer support team is available during business hours to assist you with any issues related to text messages, including opt-out requests, technical problems, or general inquiries about our SMS program.

2.7 Carrier Liability Disclaimer

Supported Carriers: Our SMS service is compatible with major U.S. wireless carriers including AT&T, Verizon, T-Mobile, Sprint, US Cellular, and most other carriers. However, not all carriers support all features of our service.

Carrier Limitations and Disclaimers:

No Carrier Liability: Wireless carriers are not liable for delayed, failed, or undelivered messages

Delivery Not Guaranteed: We cannot guarantee that messages will be delivered on time or at all due to factors outside our control, including but not limited to carrier network issues, device compatibility, signal strength, or phone settings

Network Issues: Messages may be delayed or blocked due to carrier network congestion, maintenance, outages, or technical issues

International Roaming: Messages may not be delivered if you are roaming internationally, and international data rates may apply

Device Compatibility: Some older phones or devices may not support all features of our SMS service

Spam Filters: Some carriers may filter our messages as spam; check your spam or blocked messages folder if you're not receiving expected communications

You acknowledge that wireless carriers are not liable to you or Advocate Construction for any claim related to the SMS program, and you agree to hold carriers harmless from any such claims.

2.8 Age Restriction (18+)

You must be 18 years of age or older to consent to receive SMS messages from Advocate Construction. By opting in to our SMS program, you represent and warrant that:

You are at least 18 years old

You are the owner or authorized user of the mobile phone number provided

You have the authority to agree to receive text messages at that number

If we discover that you are under 18 years of age, we will immediately remove you from our SMS program. Parents or legal guardians may not provide consent on behalf of minors under 18.

Why this matters: Under the Telephone Consumer Protection Act (TCPA) and other federal and state laws, only individuals 18 years or older can legally provide consent to receive marketing text messages. All service contracts with Advocate Construction also require customers to be 18+ as contracts with minors are not legally binding under Advocate Construction state law.

2.9 SMS Terms and Conditions

By participating in our SMS program, you agree to the following additional terms:

Mobile Number Ownership: You represent that you own the mobile phone number provided or are the authorized user with permission to receive text messages at that number. You agree to notify us immediately if you change your mobile phone number.

Accuracy of Information: You are responsible for providing accurate mobile phone number information. Advocate Construction is not responsible if you do not receive messages due to an incorrect phone number.

No Guarantee of Service: While we strive to provide reliable SMS service, we do not guarantee uninterrupted or error-free service. Technical issues may occasionally prevent message delivery.

Right to Modify or Terminate: We reserve the right to modify, suspend, or terminate the SMS program at any time, with or without notice. We may change message frequency, content, or program terms at our discretion.

Compliance with Laws: Our SMS program complies with the Telephone Consumer Protection Act (TCPA), the CAN-SPAM Act, and Illinoisstate consumer protection laws. You agree to use our SMS service in compliance with all applicable laws.

Privacy Protection: Your mobile phone number and SMS communications are protected under our Privacy Policy (see Section 2.10 below). We will never sell or rent your mobile phone number to third parties.

No Liability for Carrier Charges: You are solely responsible for any charges imposed by your wireless carrier for text message services. Advocate Construction is not responsible for carrier fees.

Unsubscribe Effectiveness: If you opt-out of SMS messages and continue to receive messages, please contact us immediately at [email protected] or call (630) 398-4600. We will investigate and resolve the issue promptly.

Changes to Terms: We may update these SMS Terms and Conditions from time to time. Continued participation in the SMS program after changes are posted constitutes your acceptance of the modified terms.

2.10 Link to Privacy Policy & Mobile Information Sharing

Your privacy is important to us. Our SMS program and the collection and use of your mobile phone number are governed by our comprehensive Privacy Policy, which includes detailed information about mobile information sharing and privacy protections.

Key Privacy Highlights:

We DO NOT sell or share your mobile phone number: Your mobile phone number will never be sold, rented, traded, or shared with third parties for their marketing purposes

Internal Use Only: Your number is used solely to communicate with you about your project and provide services you've requested

Service Provider Access: Your number may be shared with our SMS platform provider (GoHighLevel) solely for message delivery purposes under strict confidentiality agreements

No Third-Party Marketing: We will never provide your mobile number to advertisers, data brokers, or other third parties for marketing purposes

Security Measures: Your mobile phone number is stored securely with encryption and restricted access

Your Rights: You have the right to access, correct, or delete your mobile phone number from our system at any time

Email: [email protected]

Phone: (630) 398-4600

Mail: 374 Upland Dr #1st, Tukwila, WA 98188

3. SERVICES OFFERED

3.1 Scope of Services

Advocate Construction is a licensed Illinois State General Contractor providing comprehensive residential and commercial construction and remodeling services, including but not limited to:

Residential Services:

Full home remodeling and renovation

Kitchen remodeling and renovation

Bathroom remodeling and renovation

Basement remodeling and finishing

Custom home building and new construction

Home additions and extensions

Deck building and outdoor living spaces

Accessory Dwelling Units (ADUs)

Space reconfiguration and layout changes

Cabinet installation, painting, and refinishing

Custom carpentry and millwork

Flooring installation (hardwood, laminate, tile, carpet)

Roofing services

Electrical work

Plumbing

HVAC services

Painting (interior and exterior)

Siding installation

Framing

Drywall installation and repair

Countertop and backsplash installation

Tile and stonework

Permit acquisition and coordination

Commercial Services:

Office renovations

Restaurant renovations

Retail space renovations

3.3 Licensing, Bonding, and Insurance

Advocate Construction LLC maintains all required licenses, bonds, and insurance as required by Illinois State law:

3.4 Subcontractors and Third Parties

We may engage licensed and insured subcontractors, material suppliers, and other third parties to complete certain aspects of your project. All subcontractors are carefully vetted, licensed, and insured according to Illinois State requirements. We remain responsible for the quality and completion of all work performed by our subcontractors.

4. CUSTOMER OBLIGATIONS

4.1 Age and Authority

You represent and warrant that:

You are at least 18 years of age

You have the legal capacity to enter into binding contracts

If the property is not solely owned by you, you have obtained all necessary permissions from co-owners or other parties with legal interest in the property

You have authority to authorize work on the property in question

4.2 Property Access

You agree to:

Provide safe and unrestricted access to the work site during agreed-upon work hours

Provide keys, gate codes, alarm codes, or other access methods as necessary

Ensure that driveways, work areas, and access points are clear of vehicles and obstructions

Notify us of any site hazards (pets, children, elderly residents, security systems, etc.)

Maintain utilities (water, electricity, gas) at the work site unless otherwise agreed

4.3 Insurance and Permits

You agree to:

Maintain active homeowner's insurance throughout the duration of the project

Notify your insurance carrier of construction/remodeling activities if required by your policy

Allow us to obtain necessary building permits (permit costs will be included in your project estimate)

Ensure that any homeowner's association (HOA) approvals are obtained before work begins (customer responsibility unless otherwise agreed in writing)

4.4 Pets and Occupants

You agree to:

Secure or remove pets from work areas during work hours

Notify us of any aggressive or unpredictable animals on the property

Ensure the safety of any occupants (children, elderly, disabled individuals) during construction

Understand that construction sites pose safety hazards and restrict access accordingly

4.5 Accurate Information

You agree to provide:

Accurate contact information (phone, email, mailing address)

Accurate property information and dimensions

Disclosure of any known defects, hazards, or conditions that may affect the project

Timely responses to requests for decisions, selections, or approvals

5. ESTIMATES AND PROPOSALS

5.1 Free Estimates

We provide free, no-obligation in-home estimates and consultations. Estimates are provided in good faith based on the information available at the time of the site visit.

5.2 Estimate Validity

Written estimates are valid for 30 days from the date of issuance unless otherwise specified. After 30 days, we reserve the right to revise estimates to reflect changes in material costs, labor rates, or project scope.

5.3 Estimates Not Binding Until Contract Signed

Estimates and proposals are not binding contracts. No work will commence until a formal written contract is signed by both parties and the initial deposit is received.

5.4 Pricing and Changes

Estimates are based on current material costs and labor rates, which are subject to change. Final pricing may be adjusted if:

Material costs increase significantly between estimate and project start

Hidden conditions are discovered during work

Customer requests changes to project scope (change orders)

Permits require additional work not anticipated in original estimate

Unforeseen site conditions require additional labor or materials

All pricing adjustments will be documented in writing and require customer approval before proceeding.

6. CONTRACTS AND AGREEMENTS

6.1 Written Contract Required

All construction and remodeling projects require a written contract signed by both Advocate Construction and the customer. The contract will include:

Detailed scope of work

Project timeline and completion date (if applicable)

Total project cost and payment schedule

Materials and specifications

Warranty terms

Change order procedures

Cancellation and dispute resolution terms

6.2 Contract Modifications

Any modifications to the contract must be documented in writing through a formal change order process (see Section 10). Verbal agreements or modifications are not binding.

6.3 Illinois State Three-Day Cancellation Right

Under Illinois State law (RCW 19.48), customers have the right to cancel certain home improvement contracts within three (3) business days of signing without penalty. This right applies to contracts signed at a location other than Advocate Construction's principal place of business. Cancellation must be submitted in writing to the address listed in the contract.

6.4 Entire Agreement

The written contract, along with these Terms of Service and our Privacy Policy, constitute the entire agreement between you and Advocate Construction. No prior oral or written representations or agreements will be binding unless included in the written contract.

7. PAYMENT TERMS

7.1 Payment Structure

Standard Payment Schedule:

50% Deposit: Due upon contract signing before work begins

Progress Payments: Additional payments may be required at project milestones for larger projects (to be specified in individual contracts)

Final Payment: Balance due upon substantial completion and customer approval

Specific payment schedules will be outlined in your individual contract.

7.2 Accepted Payment Methods

We accept the following payment methods:

Personal checks (payable to Advocate Construction LLC)

Cashier's checks or money orders

Credit cards (Visa, MasterCard, American Express, Discover) - processing fees may apply

ACH/Bank transfers

Financing through approved third-party lenders (subject to credit approval)

7.3 Payment Plans and Financing

Payment plans may be available for qualified customers. We partner with third-party financing companies (such as Enhancify) to offer financing options, including 0% APR promotional financing for 12 months (subject to credit approval). Financing terms, rates, and conditions are determined by the lender and are not guaranteed by Advocate Construction.

Financing Disclaimer: Not all applicants will qualify for financing. Advocate Construction is not a lender and does not guarantee financing approval. Financing terms and rates are determined by the third-party lender based on creditworthiness and other factors.

7.4 Late Payments

Payments are due on the dates specified in your contract. Late payments may result in:

Late payment fees of 1.5% per month (18% annual percentage rate) on overdue balances

Suspension of work until payment is received

Additional collection costs, including reasonable attorney's fees

Loss of warranty coverage for unpaid work

7.5 Returned Checks

Returned checks (NSF) will incur a $35 processing fee plus any bank fees we incur. After a returned check, we may require certified funds for all future payments.

7.6 Liens and Legal Remedies

Illinois State law allows contractors to file mechanic's liens against your property for unpaid work. If payment is not received as agreed, we reserve the right to:

File a mechanic's lien against the property

Pursue legal action to collect payment

Report delinquent accounts to credit bureaus

Recover all costs of collection, including attorney's fees and court costs

7.7 Payment Disputes

If you dispute any charge, you must notify us in writing within 10 days of the invoice date. We will work with you to resolve the dispute promptly. Payment of undisputed amounts must continue during dispute resolution.

8. PROJECT TIMELINE AND DELAYS

8.1 Estimated Completion

Project timelines provided in estimates and contracts are good-faith estimates based on normal working conditions. We will make every reasonable effort to complete your project on schedule.

8.2 Factors That May Cause Delays

Project timelines may be extended due to factors beyond our control, including:

Weather conditions: Rain, snow, extreme temperatures, or other weather events

Permit delays: Delays in permit issuance or inspections by government authorities

Material availability: Supply chain issues, material shortages, or discontinued products

Hidden conditions: Discovery of unforeseen issues (structural problems, mold, asbestos, outdated wiring, plumbing issues, etc.)

Customer delays: Late decisions on materials, change orders, or delayed payments

Utility delays: Delays by utility companies in service disconnections or connections

Force majeure: Acts of God, natural disasters, pandemics, labor strikes, or other events beyond our reasonable control

8.3 Notice of Delays

We will notify you promptly if we anticipate any significant delays and provide revised timeline estimates.

8.4 No Liability for Delays

Advocate Construction is not liable for damages, losses, or expenses resulting from project delays caused by factors outside our reasonable control. We are not responsible for temporary living expenses, storage costs, or consequential damages related to project delays.

9. CHANGES TO PROJECT SCOPE (CHANGE ORDERS)

9.1 Change Order Process

Any changes to the original contract scope of work must be documented through a formal written change order. Change orders must include:

Detailed description of the change

Additional cost or credit to contract price

Impact on project timeline

Signatures from both Advocate Construction and customer

9.2 Changes Requested by Customer

If you request changes to materials, design, or scope of work after the contract is signed:

We will provide a written change order with pricing and timeline impact

Work on the change will not commence until the change order is signed and any additional payment is received

Change orders may extend the project timeline

9.3 Changes Required by Unforeseen Conditions

If we discover hidden conditions or unforeseen issues during construction (such as structural damage, mold, termites, code violations, outdated electrical or plumbing, etc.):

We will notify you immediately and provide photos/documentation

We will provide a written change order with pricing for necessary repairs

You may choose to approve the additional work or terminate the project (with payment due for work completed to date)

We are not responsible for the discovery or repair of hidden conditions beyond the original scope of work unless you approve a change order

9.4 Changes Required by Code or Permit

If building inspectors or permit authorities require additional work or changes to meet code requirements, these changes will be documented as change orders and are the customer's responsibility unless caused by Advocate Construction's error or omission.

10. WARRANTIES AND GUARANTEES

11. LIMITATION OF LIABILITY

11.1 Maximum Liability

TO THE FULLEST EXTENT PERMITTED BY Illinois STATE LAW, OUR TOTAL LIABILITY ARISING FROM OR RELATED TO YOUR PROJECT SHALL NOT EXCEED THE TOTAL AMOUNT PAID BY YOU UNDER THE CONTRACT FOR THE SPECIFIC WORK AT ISSUE.

11.2 Excluded Damages

WE ARE NOT LIABLE FOR:

Consequential Damages: Including but not limited to loss of use, temporary housing expenses, storage costs, lost profits, or economic losses

Indirect Damages: Any damages not directly caused by our actions or omissions

Pre-Existing Conditions: Issues, defects, or damage that existed before our work began

Hidden Conditions: Conditions not visible or discoverable during normal inspection (mold, asbestos, structural damage, termites, etc.) unless we are specifically contracted to inspect for and remediate such conditions

Third-Party Actions: Damage caused by subsequent contractors, homeowners, tenants, or other third parties

Customer-Supplied Materials: Defects, performance issues, or failures of materials supplied by customer

Permit Denials: If permits are denied by authorities for reasons beyond our control

Design Issues: Problems resulting from designs or plans provided by customer or third-party designers (unless we accepted responsibility for design in writing)

11.3 Pre-Existing Conditions and Hidden Defects

We are not responsible for discovering or repairing conditions that are not visible or apparent during normal inspection and construction, including but not limited to:

Hidden structural damage

Mold or mildew behind walls or under flooring

Asbestos, lead paint, or other hazardous materials

Outdated or non-compliant electrical or plumbing systems

Termite or pest damage

Foundation issues

Roof leaks or water damage not visible during inspection

Soil or drainage problems

If such conditions are discovered during work, we will notify you immediately and provide pricing for remediation. You may choose to authorize additional work or terminate the project with payment due for work completed.

11.4 Time Limitation

Any claims for damages must be submitted in writing within 2 years of project completion or within the warranty period, whichever is applicable. Claims submitted after this period are time-barred.

12. CANCELLATION AND TERMINATION

12.1 Customer's Right to Cancel

Three-Day Cancellation (Illinois Law): You have the right to cancel certain home improvement contracts within three (3) business days of signing if the contract was signed at a location other than our business office (RCW 19.48). To cancel, send written notice to the address in your contract. Illinois

Cancellation After Three Days: After the three-day window:

You may request cancellation by providing written notice

The 50% deposit is non-refundable if work has been scheduled or materials ordered

You will be responsible for paying for all work completed and materials purchased to date

You will be responsible for any restocking fees for materials that can be returned

If materials cannot be returned, you are responsible for the full cost

12.2 Advocate Construction's Right to Terminate

We reserve the right to terminate the contract if:

Customer fails to make payments as agreed

Customer repeatedly denies reasonable access to the work site

Customer engages in abusive, threatening, or harassing behavior toward our employees or subcontractors

Customer materially breaches the contract terms

Site conditions become unsafe for our workers

Customer provided false or misleading information

Upon termination by Advocate Construction:

All amounts due for work completed to date become immediately payable

We will provide an invoice for work completed and materials purchased

We will remove our equipment and secure the site to the extent reasonably possible

Customer remains responsible for payment of all amounts owed

12.3 Effect of Cancellation

Upon cancellation by either party:

All work stops immediately

Customer pays for all work completed and materials purchased

Any deposits applied to completed work or materials purchased are non-refundable

Advocate Construction will provide a final accounting within 14 days

Customer is responsible for securing the work site and completing or removing any unfinished work

13. DISPUTE RESOLUTION

13.1 Informal Resolution

In the event of any dispute, claim, or controversy arising out of or relating to these Terms, your contract, or our services, the parties agree to first attempt to resolve the matter through good-faith informal negotiations.

Contact us at:

Email: [email protected]

Phone: (630) 398-4600

Mail: Advocate Construction LLC, ATTN: Disputes, 827 North Ave, Glendale Heights Illinois 60139

We will work with you in good faith to resolve any issues promptly and fairly.

13.2 Mediation

If informal negotiations fail to resolve the dispute within 30 days, the parties agree to submit the dispute to non-binding mediation before pursuing litigation or arbitration. Mediation shall be conducted in King County, Illinois, by a mutually agreed-upon mediator. Each party shall bear its own costs of mediation, and the parties shall split the mediator's fees equally.

13.3 Binding Arbitration (Optional)

If mediation fails to resolve the dispute, either party may elect binding arbitration as an alternative to litigation. If arbitration is elected:

Arbitration shall be conducted under the rules of the American Arbitration Association (AAA) or JAMS

Arbitration shall take place in King County, Illinois

The arbitrator's decision shall be final and binding

Each party shall bear its own attorney's fees unless the arbitrator awards fees to the prevailing party

The arbitration award may be entered as a judgment in any court of competent jurisdiction

Either party may opt out of arbitration by providing written notice within 30 days of contract signing.

13.4 Litigation

If arbitration is not elected or is opted out of, disputes shall be resolved through litigation in the appropriate court as described in Section 13.5.

13.5 Governing Law and Venue

These Terms, your contract, and any disputes shall be governed by the laws of the State of Illinoiswithout regard to conflicts of law principles.

Any litigation shall be brought exclusively in the state or federal courts located in Illinois. Both parties consent to the personal jurisdiction and venue of these courts.

13.6 Attorney's Fees

In any litigation, arbitration, or legal proceeding to enforce these Terms or your contract, the prevailing party shall be entitled to recover its reasonable attorney's fees, court costs, and other legal expenses from the non-prevailing party.

13.7 No Class Actions

YOU AGREE THAT ANY DISPUTE RESOLUTION PROCEEDINGS WILL BE CONDUCTED ONLY ON AN INDIVIDUAL BASIS AND NOT IN A CLASS, CONSOLIDATED, OR REPRESENTATIVE ACTION. You waive any right to participate in class action lawsuits or class-wide arbitration.

14. WEBSITE USE AND INTELLECTUAL PROPERTY

14.1 Website Terms

By accessing and using https://advocateconstruction.com/ and any related websites, you agree to:

Use the website for lawful purposes only

Not interfere with or disrupt the website or servers

Not attempt to gain unauthorized access to any systems or data

Not use automated tools (bots, scrapers) to access the website

Not upload viruses, malware, or malicious code

Not misrepresent your identity or affiliation

14.2 Intellectual Property Rights

All content on our website, including but not limited to text, graphics, logos, images, videos, designs, and software, is the property of Advocate Constructionn LLC or our licensors and is protected by U.S. and international copyright, trademark, and intellectual property laws.

You may not:

Copy, reproduce, distribute, or display website content without written permission

Use our trademarks, logos, or branding without written authorization

Create derivative works based on our content

Use our content for commercial purposes without permission

14.3 Project Photos and Testimonials

With your written consent, we may:

Photograph or video your completed project

Use project photos in our marketing materials, website, and social media

Share your testimonials and reviews

Include your project in our portfolio

You may revoke consent at any time by contacting us in writing at [email protected]. We will remove your photos and testimonials within 30 days of receiving your revocation notice.

14.4 Customer-Provided Content

If you submit photos, reviews, testimonials, or other content to us, you grant Advocate Construction a non-exclusive, royalty-free, perpetual, worldwide license to use, reproduce, modify, and display that content for marketing and promotional purposes.

You represent that:

You own or have rights to any content you submit

Your content does not infringe on any third-party rights

Your content does not contain false or misleading information

15. PRIVACY AND DATA PROTECTION

15.1 Privacy Policy

Your privacy is important to us. Our collection, use, and protection of your personal information is governed by our comprehensive Privacy Policy, which is incorporated into these Terms by reference.

15.2 Information We Collect

We collect personal information including:

Name, email address, phone number (including mobile), mailing address

Property information and project details

Payment and financial information

Photos and videos of your property

Communications with us (emails, texts, calls)

Website usage data (through cookies and analytics)

15.3 How We Use Your Information

We use your information to:

Provide construction and remodeling services

Communicate with you about your project

Process payments and manage billing

Send appointment reminders and project updates

Obtain permits and coordinate with subcontractors

Send marketing communications (with your consent)

Improve our services and website

15.4 SMS/Text Message Privacy

As detailed in Section 2 above, your mobile phone number is subject to specific privacy protections:

We DO NOT sell or share your mobile phone number with third parties for marketing

Your number is used solely for legitimate business communications

You can opt-out of text messages at any time

See Section 2.10 and our Privacy Policy for complete mobile privacy details

15.5 Information Sharing

We do not sell or rent your personal information. We may share your information with:

Subcontractors and suppliers (to complete your project)

Payment processors (to process payments)

Technology service providers (website hosting, CRM, email services)

Government authorities (for permits and inspections)

Legal authorities (when required by law)

All third parties are contractually obligated to protect your information.

15.6 Data Security

We implement appropriate security measures to protect your personal information, including:

SSL/HTTPS encryption for our website

Secure storage in our GoHighLevel CRM system

Limited employee access on a need-to-know basis

Regular security audits and updates

15.7 Your Privacy Rights

You have the right to:

Access your personal information

Correct inaccurate information

Request deletion of your information (subject to legal retention requirements)

Opt-out of marketing communications

Withdraw consent for data processing

To exercise these rights, contact us at or (630) 398-4600.

15.8 Cookies and Tracking

Our website uses cookies and tracking technologies including:

Google Analytics (for website analytics)

Facebook Pixel (for advertising)

Essential cookies (for website functionality)

You can manage cookies through your browser settings. Disabling cookies may limit website functionality.

15.9 Data Retention

We retain your information for:

Active projects: Duration of project plus 10 years (for warranty and legal compliance)

Marketing contacts: Until you opt-out or request deletion

Legal records: As required by Illinois State law (typically 7-10 years)

16. DISCLAIMER OF WARRANTIES

16.1 Services Provided "As Is"

OUR WEBSITE AND SERVICES ARE PROVIDED "AS IS" AND "AS AVAILABLE" WITHOUT WARRANTIES OF ANY KIND, EITHER EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, OR NON-INFRINGEMENT.

16.2 No Guarantee of Results

We make no warranties or guarantees about:

Specific project outcomes beyond what is documented in your contract

Timing of permit approvals or inspections

The absence of hidden conditions or defects

Future property value increases

Specific energy savings or efficiency improvements

16.3 Website Accuracy

While we strive to provide accurate information on our website, we do not warrant that:

Website content is accurate, complete, or current

The website will be uninterrupted or error-free

Defects will be corrected

The website is free of viruses or malicious code

16.4 Third-Party Links

Our website may contain links to third-party websites. We are not responsible for the content, accuracy, or privacy practices of third-party websites. Use third-party websites at your own risk.

17. INDEMNIFICATION

You agree to indemnify, defend, and hold harmless Advocate Construction, its officers, directors, employees, agents, subcontractors, and affiliates from and against any and all claims, damages, losses, liabilities, costs, and expenses (including reasonable attorney's fees) arising from or related to:

Your breach of these Terms or your contract

Your violation of any law or regulation

Your violation of any third-party rights (including intellectual property, privacy, or property rights)

Your misuse of our services or website

Your failure to maintain property insurance or provide accurate information

Injuries or damages caused by your negligence or willful misconduct

Any claims by third parties arising from work performed on your property (to the extent caused by your actions or omissions)

This indemnification obligation survives termination of these Terms and your contract.

18. GENERAL PROVISIONS

18.1 Severability

If any provision of these Terms is found to be invalid, illegal, or unenforceable, the remaining provisions shall continue in full force and effect. The invalid provision shall be modified to the minimum extent necessary to make it valid and enforceable.

18.2 Waiver

Our failure to enforce any provision of these Terms does not constitute a waiver of that provision or our right to enforce it in the future. Any waiver must be in writing and signed by an authorized representative of Advocate Construction.

18.3 Assignment

You may not assign, transfer, or delegate your rights or obligations under these Terms or your contract without our prior written consent. We may assign our rights and obligations to another entity in connection with a merger, acquisition, sale of assets, or operation of law.

18.4 Force Majeure

Neither party shall be liable for failure to perform obligations due to causes beyond its reasonable control, including but not limited to acts of God, natural disasters, pandemics, government actions, labor strikes, material shortages, utility failures, or other force majeure events.

18.5 Notices

All notices required under these Terms must be in writing and delivered to:

Advocate Construction LLC 827 North Ave, Glendale Heights Illinois 60139 Email: Phone: (630) 398-4600

Notices to you will be sent to the address and contact information provided in your contract or account.

18.6 Entire Agreement

These Terms, together with your individual contract and our Privacy Policy, constitute the entire agreement between you and Advocate Construction regarding our services. These Terms supersede all prior or contemporaneous oral or written agreements, representations, or understandings.

18.7 Amendments

We reserve the right to update or modify these Terms at any time by posting the revised Terms on our website with a new "Last Updated" date. Material changes will be communicated to active customers via email or text message. Your continued use of our services after changes are posted constitutes acceptance of the revised Terms.

18.8 Survival

Provisions of these Terms that by their nature should survive termination shall survive, including but not limited to: warranties, limitation of liability, indemnification, dispute resolution, governing law, and intellectual property rights.

18.9 Relationship of Parties

These Terms do not create any partnership, joint venture, employment, or agency relationship between you and Advocate Construction. We are an independent contractor for all purposes.

18.10 No Third-Party Beneficiaries

These Terms are for the sole benefit of you and Advocate Construction. No third party has any rights to enforce these Terms or any benefits hereunder.

19. CONTACT INFORMATION

For questions, concerns, or customer support regarding these Terms of Service:

Advocate Construction LLC 827 North Ave, Glendale Heights Illinois 60139

Phone: (630) 398-4600 Email: Website: https://advocateconstruction.com/

Business Hours: Monday - Friday: 9:00 AM - 5:00 PM Saturday - Sunday: Closed

Owner/CEO: Kurt COO

For SMS/Text Message Support: See Section 2.6 For Privacy Inquiries: See Section 15 and our Privacy Policy

20. ACKNOWLEDGMENT AND CONSENT

By using our website, submitting contact forms, requesting estimates, scheduling consultations, signing contracts, opting in to SMS messages, or otherwise engaging with Advocate Construction's services, you acknowledge that:

You have read and understood these Terms of Service in their entirety

You agree to be bound by these Terms and our Privacy Policy

You are at least 18 years of age and have the legal capacity to enter into binding contracts

You understand the SMS Terms and Conditions, including opt-in, opt-out, message frequency, carrier disclaimers, age restrictions, and privacy protections

You understand your rights and obligations as outlined in these Terms

You consent to electronic communications and notices as described herein

You understand and accept the warranties, limitations of liability, and dispute resolution provisions

Last Reviewed: 6 6, 2026

Document Control: Version: 1.0 Approved By: Kurt COO, Founder & CEO Date: 6 6, 2026

These Terms of Service are intended to comply with Illinois State construction law, the Telephone Consumer Protection Act (TCPA), CAN-SPAM Act, consumer protection laws, and other applicable federal and state regulations. This document should be reviewed by legal counsel before publication to ensure full compliance with all applicable laws and to address any specific business circumstances unique to Advocate Construction LLC.

© 2026 Advocate Construction LLC. All Rights Reserved.